The case involves an appeal against the order passed by the Adjudicating Authority, which rejected the Appellant's Section 9 application due to a pre-existing dispute. The Appellant, a sub-contractor, was issued a Letter of Intent by the Corporate Debtor for chimney construction. The Appellant claims entitlement to Idle Charges due to delays, leading to correspondences and a meeting on 2018-10-01 where the Appellant was asked to submit relevant documents. A legal notice was issued on 2019-01-11 for payment of Idle Charges.
R.S. Pabbla Constructions Pvt. Ltd. (Appellant) filed an appeal against the rejection of its Section 9 application by the Adjudicating Authority. The rejection was based on the existence of a pre-existing dispute with ISGEC Heavy Engineering Ltd. (Corporate Debtor). Pabbla Constructions, a sub-contractor, was contracted by ISGEC for chimney construction, evidenced by a Letter of Intent. Pabbla claims entitlement to 'Idle Charges' due to delays, leading to correspondence and a meeting on 2018-10-01 where ISGEC requested relevant documents. Pabbla issued a legal notice on 2019-01-11 demanding payment for these charges. ISGEC disputed the claim, asserting in a letter dated 2019-02-02 that Pabbla was not entitled to any money and was attempting to 'arm-twist' them. The
…Sign in to view the parties.
A meeting was held where the Operational…
The Operational Creditor issued a legal notice…
Sign in to view related legal provisions.
The case involves an appeal against the order passed by the Adjudicating Authority, which rejected the Appellant's Section 9 application due to a pre-existing dispute. The Appellant, a sub-contractor, was issued a Letter of Intent by the Corporate Debtor for chimney construction. The Appellant claims entitlement to Idle Charges due to delays, leading to correspondences and a meeting on 2018-10-01 where the Appellant was asked to submit relevant documents. A legal notice was issued on 2019-01-11 for payment of Idle Charges.
R.S. Pabbla Constructions Pvt. Ltd. (Appellant) filed an appeal against the rejection of its Section 9 application by the Adjudicating Authority. The rejection was based on the existence of a pre-existing dispute with ISGEC Heavy Engineering Ltd. (Corporate Debtor). Pabbla Constructions, a sub-contractor, was contracted by ISGEC for chimney construction, evidenced by a Letter of Intent. Pabbla claims entitlement to 'Idle Charges' due to delays, leading to correspondence and a meeting on 2018-10-01 where ISGEC requested relevant documents. Pabbla issued a legal notice on 2019-01-11 demanding payment for these charges. ISGEC disputed the claim, asserting in a letter dated 2019-02-02 that Pabbla was not entitled to any money and was attempting to 'arm-twist' them. The
…A meeting was held where the Operational…
The Operational Creditor issued a legal notice…
Sign in to view related legal provisions.